Queensland Consolidated Acts
[Index]
[Table]
[Search]
[Search this Act]
[Notes]
[Noteup]
[Previous]
[Download]
[Help]
QUEENSLAND BUILDING AND CONSTRUCTION COMMISSION ACT 1991 - SCHEDULE 2
SCHEDULE 2 – Dictionary
"accumulate" , for part 3E , see section 67AQ .
"administering authority" , for part 3E , see section 67AQ .
"administration services" , for building work or tribunal work, includes the
following—
(a) preparing tender documentation and calling and selecting
tenders;
(b) arranging and conducting on-site meetings and inspections;
(c)
arranging payment of subcontractors;
(d) arranging for certificates,
including certificates from a local government, to be issued;
(e)
administration for the work usually carried out by— (i) a construction
manager; or
(ii) a project manager under a project management agreement;
(f)
other administration for the work usually carried out by a licensed contractor
in the course of the contractor’s business.
"Advisory Service" ...
"advisory services" , for building work or tribunal work, includes the
provision of advice or a report about building work other than— (a) the
carrying out of a completed building inspection; or
(b) the inspection or
investigation of a building, and the provision of advice or a report, for the
following— (i) termite management systems for the building;
(ii) termite
infestation in the building.
"alternative solution" ...
"apprentice" see the Further Education and Training Act 2014 , schedule 1 .
"appropriate insurance premium" , for part 5 , see section 67WA .
"approved form" means a form approved by the chief executive or the
commissioner under section 115C .
"approved security provider" , for part 4A , see section 67A .
"architect" means a person registered as an architect under the
Architects Act 2002 .
"assessment manager" means an assessment manager under the Planning Act .
"assistance" , for part 5 , see section 67WA .
"associated insurable work" , for part 5 , see section 67WD .
"associated with" , in relation to a building or other structure, see
section 74AA .
"authority" ...
"automated bleeding device" means an automatic device used for the purposes of
draining or bleeding or removing fluid or gas.
"banned individual" see section 67AC .
"board" means the Queensland Building and Construction Board established under
section 10 .
"board’s policies" ...
"building" — (a) generally, includes any fixed structure; or Examples of a
fixed structure— • a fence other than a temporary fence
• a water
tank connected to the stormwater system for a building
• an in-ground
swimming pool or an above-ground pool fixed to the ground
(b) for part 6AA
, see section 74AA ; or
(c) for schedule 1B , see schedule 1B , section 1 .
"Building Code of Australia" see the Building Act 1975 , section 12 .
"building contract" — (a) for part 3E —see section 67AAA ; and
(b) for
part 4A —see section 67AAA ; and
(c) for schedule 1 , part 2 —see
schedule 1 , section 8 ; and
(d) otherwise—means a contract or other
arrangement for carrying out building work in Queensland.
"building contractor" — (a) generally, means a person who carries on a
business that consists of or includes carrying out building work, and includes
a subcontractor who carries out building work for a building contractor; but
(b) for schedule 1B , see schedule 1B , section 1 .
"building dispute" means— (a) a domestic building dispute; or
(b) a minor
commercial building dispute; or
(c) a major commercial building dispute if
the parties to the dispute consent to the dispute being heard by the tribunal
under section 79 .
"building owner" — (a) generally, means a person for whom tribunal work is
to be, is being or has been carried out, but does not include a building
contractor for whom tribunal work is carried out by a subcontractor; but
(b)
for schedule 1B , see schedule 1B , section 1 .
"building product" see section 74AB (1) .
"building product undertaking" , for part 6AA , see section 74AO (1) .
"building site" — (a) generally, means a place where building work has been,
is being, or is to be, carried out; but
(b) for schedule 1B , see schedule 1B
, section 1 .
"building work" means— (a) the erection or construction of a building; or
(b) the renovation, alteration, extension, improvement or repair of a
building; or
(c) the provision of lighting, heating, ventilation, air
conditioning, water supply, sewerage or drainage in connection with a
building; or
(e) any site work (including the construction of retaining
structures) related to work of a kind referred to above; or
(f) the
preparation of plans or specifications for the performance of building work;
or
(fa) contract administration carried out by a person in relation to the
construction of a building designed by the person; or
(g) fire protection
work; or
(ga) mechanical services work; or
(h) carrying out site testing and
classification in preparation for the erection or construction of a building
on the site; or
(i) carrying out a completed building inspection; or
(j) the
inspection or investigation of a building, and the provision of advice or a
report, for the following— (i) termite management systems for the building;
(ii) termite infestation in the building;
but does not include work of a kind
excluded by regulation from the ambit of this definition.
"building work services" means 1 or more of the following for building work—
(a) administration services;
(b) advisory services;
(c) management services;
(d) supervisory services.
"calling" includes a craft, manufacture, occupation, trade, undertaking or
vocation.
"carry out" , for building work (other than for part 4A ) means any of the
following— (a) carry out the work personally;
(b) directly or indirectly
cause the work to be carried out;
(c) provide building work services for the
work.
"carry out building work" , for part 4A , see section 67A .
"carry out tier 1 defective work" see section 67AB (2) .
"certificate of inspection" , for schedule 1B , see schedule 1B , section 1 .
"code of practice" , for part 6AA , see section 74AA .
"commercial building contract" , for part 4A , see section 67A .
"commercial building dispute" means— (a) a claim or dispute arising between
a building owner and a building contractor relating to the performance of
reviewable commercial work or a contract for the performance of reviewable
commercial work; or
(b) a claim or dispute arising between 2 or more building
contractors relating to the performance of reviewable commercial work or a
contract for the performance of reviewable commercial work; or
(c) a claim or
dispute in negligence, nuisance or trespass related to the performance of
reviewable commercial work other than a claim for personal injuries; or
(d) a
claim or dispute arising between a building owner or a building contractor and
any 1 or more of the following relating to the performance of reviewable
commercial work or a contract for the performance of reviewable commercial
work— (i) an architect;
(ii) an engineer;
(iii) a surveyor;
(iv) a
quantity surveyor;
(v) an electrician or an electrical contractor;
(vi) a
supplier or manufacturer of materials used in the tribunal work.
"commission" means the Queensland Building and Construction Commission
established under section 5 .
"commissioner" means the commissioner of the commission.
"company" means any body corporate.
"completed building inspection" means the inspection or investigation of, and
the provision of advice or a report about, the following class 1a or 10
buildings under the Building Code of Australia— (a) a building for which
there is no current contract between a building contractor and a consumer
because the contract has been completed; Example— an existing detached
house that has previously been occupied or that has recently been built
(b)
a building on which work is not being carried out because the contract under
which it was being carried out has been terminated; Example— a detached
house on which a building contractor has stopped building work in breach of
the terms of a contract with a consumer and the consumer has terminated the
contract
(c) a building on which work is being, or was, carried out but not
under a contract between a building contractor and a consumer. Example— a
detached house being built by, or that was built by, a building contractor but
not under a contract with a particular consumer This is known in the building
industry as “a speccy”.
Editor’s note— Class 1a includes a
detached house, a row house, a terrace house, a town house and a villa unit.
Class 10 includes non-habitable buildings such as private garages, carports
and sheds.
"compliance purpose" , for part 9 , see section 103G .
"condition" includes a limitation or restriction.
"consequential damage" see section 71H .
"construction management contract" means a contract under which a principal
engages a construction manager to provide building work services for building
work carried out for the principal under construction management trade
contracts.
"construction management trade contract" see section 67A .
"construction manager" means a person who provides building work services for
the carrying out of building work for a principal under a construction
management contract.
"consumer" — (a) generally, means a person for whom building work is carried
out, but does not include a building contractor for whom building work is
carried out by a subcontractor; but
(b) for part 5 , see section 67WA .
"consumer building guide" , for schedule 1B , see schedule 1B , section 1 .
"contract" , for part 7 , means a contract for carrying out tribunal work.
"contract administration" , in relation to building work designed by a person,
includes the following— (a) preparing tender documentation and calling and
selecting tenders;
(b) preparing, or helping the person’s clients with the
preparation of, contracts;
(c) preparing additional documentation for the
person’s clients or building contractors;
(d) arranging and conducting
on-site meetings and inspections;
(e) arranging progress payments;
(f)
arranging for certificates, including certificates from a local government, to
be issued;
(g) providing advice and help to the person’s clients including
during the maintenance period allowed under a contract.
"contracted party" , for part 4A , see section 67A .
"contracted services" , for schedule 1B , see schedule 1B , section 1 .
"contracting party" see section 67A .
"contractor’s licence" see section 30 (1) .
"contract price" , for a building contract, means the amount payable under the
contract for carrying out the building work the subject of the contract,
including, if the contract has been the subject of a variation, the contract
as varied.
"convicted company officer" means a person who has been convicted of an
offence under the Corporations Act 2001 (Cwlth) , section 596 (1) (b) or (c) .
"conviction" , for part 3E , see section 67AQ .
"cooling tower" means a device for lowering— (a) the temperature of
recirculated water by bringing the water into contact with fan-forced, or
fan-induced, atmospheric air; or
(b) the temperature of water, a refrigerant
or other fluid in a pipe or other container by bringing recirculated water and
fan-forced, or fan-induced, atmospheric air into contact with the pipe or
container.
"cost escalation clause" ...
"cost plus contract" , for schedule 1B , see schedule 1B , section 1 .
"decision" includes an order or direction.
"default certificate" see section 67AQ .
"defective" , in relation to building work, includes faulty or unsatisfactory.
"defects document" , for schedule 1B , see schedule 1B , section 1 .
"defects liability period" , for part 4A , see section 67A .
"demerit matter" see section 67AQ .
"demerit offence" , for part 3E , see section 67AR .
"demerit points" see section 67AQ .
"design work" means— (a) the preparation of plans or specifications for
building work; or
(b) professional advice in relation to building work.
"detached dwelling" , for schedule 1B , see schedule 1B , section 1 .
"determination" ...
"developer register" , for part 8 , see section 98 .
"development approval" means a development approval under the Planning Act .
"direction to rectify or remedy" means a direction given under section 72 (2)
.
"disciplinary proceeding" ...
"display home" ...
"disqualified individual" see section 67AU .
"document certification requirement" , for part 9 , see section 105Q (6) .
"document production requirement" , for part 9 , see section 105Q (2) .
"domestic building contract" , for schedule 1B , see schedule 1B , section 3 .
"domestic building dispute" means— (a) a claim or dispute arising between a
building owner and a building contractor relating to the performance of
reviewable domestic work or a contract for the performance of reviewable
domestic work; or
(b) a claim or dispute arising between 2 or more building
contractors relating to the performance of reviewable domestic work or a
contract for the performance of reviewable domestic work; or
(c) a claim or
dispute in negligence, nuisance or trespass related to the performance of
reviewable domestic work other than a claim for personal injuries; or
(d) a
claim or dispute arising between a building owner or a building contractor and
any 1 or more of the following relating to the performance of reviewable
domestic work or a contract for the performance of reviewable domestic work—
(i) an architect;
(ii) an engineer;
(iii) a surveyor;
(iv) a quantity
surveyor;
(v) an electrician or an electrical contractor;
(vi) a supplier or
manufacturer of materials used in the tribunal work.
"domestic building work" see schedule 1B , section 4 .
"draftsperson" , for schedule 1B , see schedule 1B , section 1 .
"drainage" see the Plumbing and Drainage Act 2018 , schedule 1 .
"electronic document" ...
"employee of the employing office" see section 29F (2) .
"employing office" means the Queensland Building and Construction Employing
Office established under section 29A .
"enforcement debtor" see the State Penalties Enforcement Act 1999 , schedule 2
.
"enforcement order" see the State Penalties Enforcement Act 1999 , schedule 2
.
"engineer" means a person who is a registered professional engineer under the
Professional Engineers Act 2002 .
"examine" , for part 9 , see section 103G .
"excluded building work" , for schedule 1B , see schedule 1B , section 1 .
"excluded company" see section 56AC (6) .
"excluded individual" , for a relevant event, see section 56AC (3) and (4) .
"exclusion notice" see section 50CB (1) .
"executive officer" , for part 2A , means the executive officer of the
employing office appointed under section 29D .
"executive officer" , of a company, means a person who is— (a) a director or
secretary of the company; or
(b) a person who is concerned with, or takes
part in, the company’s management, whether or not the person is a director
or secretary of the company or the person’s position is given the name of
executive officer.
"exempt building work" ...
"farm building" , for schedule 1B , see schedule 1B , section 1 .
"field work" means— (a) a site investigation; or
(b) a site assessment; or
(c) soil sampling; or
(d) soil collection.
"fire protection equipment" , for a building, means equipment for protecting
all or part of the building from fire that consists of, or is a system
comprised of, 1 or more of the following— (a) a portable firefighting
appliance, including, for example, a wheeled fire-extinguisher, fire hose or
portable fire-extinguisher;
(b) a fire hydrant system, with or without a
pump;
(c) a fire hose reel system, with or without a pump;
(d) a fire or
smoke detection system, heat or smoke alarm or another alarm system or
emergency warning and communication system;
(e) a fire suppression system or
fire sprinkler system, whether solid-based, liquid-based or gas-based;
(f) a
fire door, fire shutter or fire damper assembly;
(g) a fire or smoke wall;
(h) a fire collar;
(i) a fire penetration joint or seal;
(j) emergency
lighting.
"fire protection occupational licence" see section 30C (1) and (2) .
"fire protection system" ...
"fire protection work" see section 30CA .
"foundations data" , for schedule 1B , see schedule 1B , section 8 .
"general power" , for part 9 , see section 105L (1) .
"government entity" see the Public Sector Act 2022 , section 276 .
"help requirement" , for part 9 , see section 105M (1) .
"home" , for schedule 1B , see schedule 1B , section 9 .
"home-building contract" ...
"identity card" , for part 9 , see section 103G .
"incomplete" , for part 5 , see section 67WA .
"industrial instrument" see the Industrial Relations Act 2016 , schedule 5 .
"influential person" see section 4AA .
"information notice" , for part 9 , see section 103G .
"infringement notice" see section 67AQ .
"infringement notice offence" see the State Penalties Enforcement Act 1999 ,
schedule 2 .
"insolvent under administration" ...
"install" and
"installer" , for part 6AA , see section 74AA .
"insurable value" , for part 5 , see section 67WA .
"insurance notification form" means a form approved by the commission on which
information about building work is submitted to the commission for covering
the work under the statutory insurance scheme.
"intended use" , for a building product, see section 74AA .
"internal review application" , for part 7 , division 3 , subdivision 1 , see
section 85A .
"internal review decision" , for part 7 , division 3 , subdivision 1 , see
section 86C (1) .
"internal reviewer" , for part 7 , division 3 , subdivision 1 , see
section 85A .
"interstate or New Zealand licence" means a licence granted by an interstate
or New Zealand licensing authority that authorises the carrying out of
building work that is equivalent, or substantially equivalent, to building
work authorised under a licence under this Act.
"interstate or New Zealand licensing authority" means an entity established
under a law of another State or New Zealand having functions similar to the
commission’s functions for granting licences under this Act.
"judgment debt" see section 67AS .
"level 1 regulated contract" , for schedule 1B , see schedule 1B , section 6 .
"level 2 regulated contract" , for schedule 1B , see schedule 1B , section 7 .
"licence" means a licence under this Act.
"licence card" means a licence card issued under section 34 .
"licence certificate" means a licence certificate issued under section 34 .
"licensed builder" means a person who is a licensed builder under the
regulations.
"licensed contractor" means a person who holds a contractor’s licence.
"licensed supervisor" , for building work, means a person who holds a licence
under this Act authorising supervision of building work of the relevant class.
"licensee" means a person who holds a licence.
"licensee register" , for part 8 , see section 98 .
"major commercial building dispute" means a commercial building dispute where
either the claim or the counterclaim exceeds $50,000.
"major domestic building work" ...
"manage" , for schedule 1B , see schedule 1B , section 1 .
"management services" , for building work or tribunal work, includes— (a)
coordinating the scheduling of the work by building contractors including as
agent for another person; and
(b) management for the work usually carried out
by— (i) a construction manager; or
(ii) a project manager under a project
management agreement; and
(c) other management for the work usually carried
out by a licensed contractor in the course of the contractor’s business.
"mechanical services occupational licence" see section 30D (1) and (2) .
"mechanical services work" means— (a) the construction, installation,
replacement, repair, alteration, maintenance, testing or commissioning of a
mechanical heating or cooling system in a building, that is associated with
the heating or cooling of that building and includes the construction,
installation, replacement, repair, alteration, maintenance, testing or
commissioning of— (i) a valve, regulator, register, pipe, tank, heating or
cooling pipe or surface, solid fuel heater, coil or other item that is used in
the system; and
(ii) in relation to a cooling tower—a water pipe, valve,
pump, automated dosing device or automated bleeding device or any other
mechanical component that affects the cooling tower's cooling water flow rate
or wastewater disposal; and
(b) the construction, installation, replacement,
repair, alteration, maintenance, testing and commissioning of a medical gas
system; and
(c) any design work that is— (i) incidental to, or associated
with work mentioned in paragraph (a) ; and
(ii) prescribed by regulation;
but
does not include— (d) gas work regulated under the
Petroleum and Gas (Production and Safety) Act 2004 ; or
(e) any treatment of
cooling water; or
(f) the connection or disconnection of a system mentioned
in paragraph (a) or (b) from a water supply other than disconnection of the
system from a water supply at an isolating valve adjacent to a mechanical
component of that system; or
(g) design work that is a professional
engineering service under the Professional Engineers Act 2002 ; or
(h)
manufacturing of pipe or ducting or components manufactured off-site; or
(i)
installation of a single head split system; or
(j) installing ductwork and
enclosures for air-conditioning, air handling and mechanical ventilation
systems; or
(k) any other work prescribed by regulation.
"medical gas" means any gas or mixture of gases or other substance or process
used for hospital or medical use that is supplied to, removed from or
conducted at, a hospital or other place where medical procedures are carried
out, by way of a pipeline reticulation system and includes oxygen, helium,
nitrous oxide, nitrogen, medical air, surgical tool gas, carbon dioxide and
common mixtures of those gases as well as anaesthesia waste.
"medical gas system" means any fixed component used— (a) in a reticulation
system for the supply or removal of medical gas from the gas source to a wall
outlet; and
(b) for patient care, therapeutic, diagnostic purposes or
surgical tools.
"member" means member of the board.
"minimum financial requirements" means the financial requirements prescribed
by regulation.
"minor commercial building dispute" means a commercial building dispute where
neither the claim nor the counterclaim exceeds $50,000.
"minor domestic building dispute" means a domestic building dispute where
neither the claim nor the counterclaim exceeds $10,000.
"mixed-purpose contract" , for schedule 1B , see schedule 1B , section 1 .
"nominated supervisor" ...
"nominee" , in relation to a company, means an officer or employee of the
company nominated by the company to have the general supervision of building
work to be carried out under a licence.
"nominee supervisor" means a person who holds a nominee supervisor’s
licence.
"nominee supervisor’s licence" see section 30A (1) .
"non-compliance risk" , for part 6AA , see section 74AA .
"non-conforming building product" see section 74AB (2) .
"notifiable incident" means— (a) the death or serious injury or illness of a
person; or
(b) an incident that exposes a person to a risk of serious injury
or illness. Example for paragraph (b)— the collapse or partial collapse of
a building
"occupational licence" means a licence or registration for an occupation
relating to building work that is— (a) given to a person under an Act
prescribed by regulation; and
(b) required by the person to carry out the
occupation.
"occupier" , for part 9 , see section 103G .
"offence warning" , for part 9 , see section 103G .
"optional additional cover" , for part 5 , see section 67Z (4) .
"owner" — (a) of land generally, means— (i) for freehold land—the
registered owner of the land under the Land Title Act 1994 ; or
(ii) for land
held under a statutory lease or licence giving a right to possession of the
land—the lessee or licensee; and
(b) of land, for part 3 , division 8
—see also section 43D ; and
(c) of a seized thing under part 9 —see
section 103G .
"owner-builder course" , for part 3 , division 8 , see section 43D .
"owner-builder permit" see section 43E .
"owner-builder register" , for part 8 , see section 98 .
"owner-builder work" see section 43D .
"payment claim" , for part 4A , see section 67A .
"performance solution" see the Building Act 1975 , schedule 2 .
"period of 3 years" , for part 3E , see section 67AQ .
"permanently excluded individual" see section 58 .
"permitted individual" ...
"permittee" means the holder of an owner-builder permit under this Act.
"personal details requirement" , for part 9 , see section 105O (5) .
"personally supervise" , in relation to building work, means personally
exercise control over the work by overseeing and directing the work to ensure
it is— (a) in accordance with the plans and specifications set out in the
contract for the work; and
(b) of a standard expected of a competent holder
of a contractor’s licence of the relevant class.
"person in control" , for part 9 , see section 103G .
"person in the chain of responsibility" , for a building product, see
section 74AE .
"PIN" see section 34A .
"place" , for part 9 , see section 103G .
"Planning Act" means the Planning Act 2016 .
"plumbing" see the Plumbing and Drainage Act 2018 , schedule 1 .
"practical completion" , for schedule 1B , see schedule 1B , section 1 .
"practical completion" , for part 4A , see section 67A .
"premises" , for part 9 , see section 103G .
"primary insurable work" , for part 5 , see section 67WC .
"prime cost item" , for schedule 1B , see schedule 1B , section 1 .
"principal" see section 67A .
"private sector entity" means an entity that is not owned, either wholly or
partly, by the State, the Commonwealth or a local government, or any of their
authorities or agencies.
"progress payment" — (a) for part 4A , see section 67A ; and
(b) for
schedule 1B , see schedule 1B , section 1 .
"project management agreement" means a contract under which a principal
engages a project manager to provide building work services for building work
carried out for the principal other than under construction management trade
contracts.
"project manager" means a person who provides building work services for the
carrying out of building work for a principal under a project management
agreement.
"provisional sum" , for schedule 1B , see schedule 1B , section 10 .
"public place" , for part 9 , see section 103G .
"public-private partnership" means an arrangement between the following
entities with the purpose of financing, designing, constructing, maintaining
or operating public infrastructure— (a) the State, the Commonwealth or a
local government, or any of their authorities or agencies;
(b) 1 or more
private sector entities.
"qualified accountant" see section 50CA (1) .
"Real Property Acts" ...
"reasonably believes" means believes on grounds that are reasonable in the
circumstances.
"reasonably practicable" , for part 6AA , see section 74AA .
"reasonably suspects" , for part 9 , see section 103G .
"recall order" , for part 6AA , see section 74AW (1) .
"recorded conviction" , for an indictable offence, does not include a finding
of guilt, or the acceptance of a plea of guilty, by a court, in relation to
the offence, without recording a conviction for the offence.
"rectify" building work means to remedy defective building work or to complete
incomplete building work.
"registrar" — (a) for part 3E —see section 67AQ ; or
(b)
otherwise—means the principal registrar under the Tribunal Act.
"registrar of titles" , for land that is not under the Land Title Act 1994 ,
means the officer responsible for keeping a register for the land.
"regulated amount" , for schedule 1B , see schedule 1B , section 1 .
"regulated contract" , for schedule 1B , see schedule 1B , section 5 .
"related roofed building" , for part 5 , see section 67WF .
"relevant Act" , for part 9 , see section 103G .
"relevant bankruptcy event" see section 56AC (1) (a) .
"relevant company event" see section 56AC (2) (b) .
"relevant details" , for part 3A , division 4 , see section 56AI (2) .
"relevant entity" , for part 9A , see section 108AA (1) .
"relevant event" means a relevant bankruptcy event or a relevant company
event.
"relevant officer" , of the commission, means— (a) an employee of the
employing office or of another government entity performing work for the
commission under a work performance arrangement; or
(b) an officer or
employee of the commission.
"relevant regulatory provisions" , for part 6AA , see section 74AA .
"relevant work" , for part 6AA , see section 74AA .
"renewal day" , for a licence, means the day the licence is due to be renewed.
"representation" , for part 6AA , see section 74AA .
"residence" , for part 5 , see section 67WE .
"residential construction work" see section 67WA .
"residential unit" means a part of a building designed for separate occupation
as a residence.
"resident owner" , for schedule 1B , see schedule 1B , section 1 .
"responsible person" , for part 6AA , see section 74AA .
"retention amount" , for part 4A , see section 67A .
"review" means review by the tribunal.
"reviewable commercial work" means tribunal work other than reviewable
domestic work.
"reviewable decision" — (a) for part 7 , division 3 , subdivision 1 , see
section 86 ; or
(b) for part 7 , division 3 , subdivision 2 , see section 86E
.
"reviewable domestic work" means domestic building work under schedule 1B ,
section 4 , except that for applying schedule 1B , section 4 (8) , the
definition
"excluded building work" under the schedule is taken not to mean anything
mentioned in paragraph (b) , (c) or (d) of that definition.
"safe" , for part 6AA , see section 74AA .
"safety risk" , for part 6AA , see section 74AA .
"schedule section" , for schedule 1B , see schedule 1B , section 1 .
"security" , for part 4A , see section 67A .
"seized thing" , for part 9 , see section 103G .
"serious injury or illness" , of a person, means an injury or illness
requiring the person to have— (a) immediate treatment as an inpatient in a
hospital; or
(b) immediate treatment for— (i) the amputation of any part of
his or her body; or
(ii) a serious head injury; or
(iii) a serious eye
injury; or
(iv) a serious burn; or
(v) the separation of his or her skin
from an underlying tissue (for example, degloving or scalping); or
(vi) a
spinal injury; or
(vii) the loss of a bodily function; or
(viii) serious
lacerations; or
(c) medical treatment within 48 hours of exposure to a
substance.
"Service Trades Council" means the Service Trades Council continued in
existence under the Plumbing and Drainage Act 2018 , section 105 .
"site classification" means the classification of a site, or the
reclassification of a site, under a standard directed to ensuring the
appropriate selection or design of footings.
"site supervisor" means a person who holds a site supervisor’s licence.
"site supervisor’s licence" see section 30B (1) and (2) .
"site testing" means— (a) field work for soil testing or site
classification; or
(b) laboratory testing of soil.
"special purpose vehicle" means an entity— (a) established for the purpose
of carrying out a public-private partnership; and
(b) declared by the
Treasurer by gazette notice to be a special purpose vehicle for this Act.
"speculative residential construction work" , for part 5 , see section 67WA .
"spent conviction" ...
"SPER" , for part 3E , see section 67AQ .
"statutory insurance scheme" means the insurance scheme established under part
5 .
"statutory warranties" , for schedule 1B , see schedule 1B , section 1 .
"subcontract" , for part 4A , see section 67A .
"subcontractor" — (a) for part 7 —means— (i) a building contractor who
carries out tribunal work for another building contractor; or
(ii) a building
contractor who carries out tribunal work for another person under a
construction management trade contract under section 67B ; and
(b) for
schedule 1B , see schedule 1B , section 1 .
"subject work" , for schedule 1B , see schedule 1B , section 1 .
"supervisor’s licence" ...
"supervisory services" , for building work or tribunal work, includes— (a)
the development, implementation and management of a system for the supervision
of the work; and
(b) the coordination or management of persons undertaking
the supervision of the work; and
(c) the personal supervision of the work;
and
(d) any other supervision of building work under this Act.
"term of ban" see section 67AO .
"term of disqualification" , for part 3E , see section 67AZM .
"tier 1 defective work" see section 67AB (1) .
"trade licence" ...
"trainee" see the Further Education and Training Act 2014 , schedule 1 .
"tribunal" means QCAT.
"Tribunal Act" ...
"tribunal work" see sections 75 and 76 .
"undertake to carry out" , for building work, means any of the following—
(a) enter into a contract to carry out the work;
(b) submit a tender to carry
out the work;
(c) make an offer to carry out the building work.
"unsatisfied" , in relation to a judgment debt, see section 67AT .
"valuable instrument" , for part 4A , see section 67A .
"value" of building work means an amount representing the reasonable cost to a
consumer of having the work carried out by a licensed contractor on the basis
that all building materials are to be supplied by the contractor (whether or
not the work is in fact carried out by a licensed contractor on that basis).
"variation" , for part 4A , see section 67A .
"warning statement" , for part 6AA , see section 74AZC (1) .
"work performance arrangement" means an arrangement under which an employee of
a government entity performs work for another government entity.
"written form" , for schedule 1B , see schedule 1B , section 1 .
AustLII: Copyright Policy
| Disclaimers
| Privacy Policy
| Feedback